During a recent soccer game, my seven-year-old son took the ball squarely in the face. But, he walked it off and continued playing. Contractors must do the same with changes.
In 2006, under a contract with NAVFAC for repairs to a wastewater treatment system at Naval Station Guantanamo Bay Cuba, the Contractor encountered differing site conditions. NAVFAC did not issue a suspension or stop work order, but the Contractor stopped working awaiting responses to RFIs. NAVFAC did not respond to all the RFIs. So, the Contractor submitted a certified claim, but the Contractor never resumed work. The Contractor should have continued working.
Under the Federal Acquisition Regulations, the Contractor is obligated to “prosecute the work diligently” and continue performance pending the outcome of a claim. (FAR 52.211-10 and 52.233-1(i)). Doing so not only mitigates potential delays and damages, but it ensures that when a claim is submitted, a “sum certain” (i.e., showing of damage) is possible.
In this case, the Contractor’s claim submission was premature and the Contractor’s refusal to perform directed or constructive changes pending the promise of payment precluded the ASBCA from having any power to resolve the dispute. The ASBCA dismissed the Contractor’s appeal because the Contractor sought future damages for work it had not yet performed. At worst, NAVFAC could have terminated the Contractor for default.
Appeal of Islands Mechanical Contractor, Inc., ASBCA No. 59655 (April 13, 2017)
Changes Made After Substantial Completion Did Not Extend Overall Project Time
Contractors take heed – a time extension may be issued after substantial completion for specific work and the Government can still assess […]
One-Sided Construction Arbitration Clause Valid in Virginia
When it’s time to butt heads, know how the local turf (court) will interpret the clause.
Manage the Risk of Construction Changes
Almost any problem on a construction project can be traced to one of two things: changes or delays (even delays are really just changes). As in life, embrace and manage the change don’t run from it.
Want Your Profit? Prove a Constructive Change, Not a Suspension of Work.
What’s the Difference Between a Suspension of Work and a Constructive Change? For federal contractors, there are two main differences: . . .
No Special Defenses to Arbitration Agreements
Arbitration agreements, whether they are separate or part of a larger agreement, are contracts – an enforceable set of promises between parties. […]
How to Find (and Confirm) the Plain Meaning in a Contract
Contract formation confirms the parties understand and agree to all the essential terms. When that understanding and agreement fades, how do you […]
Navigating the Requirements for Claims against Virginia Public Entities
Contractors making claims against Virginia public entities must follow ALL applicable requirements. Such requirements may be found in several places, so check […]
Virginia General Contractors Not Protected from Pre-Work Claim Waivers
On March 2, 2018, the Governor approved an act of the Virginia General Assembly to make unenforceable pre-work waivers of lien rights […]
Adding Terms to a Government Contract without Saying So
Imagine an incredulous Contractor asking, “Show me in the Contract where it says I’m supposed to do X?” The Government Contracting Officer smugly answers, “even though the Contract doesn’t say so, you must do it anyway.” Is that even possible, when, how?
