Contractors take heed – a time extension may be issued after substantial completion for specific work and the Government can still assess liquidated damages.

Under a contract with the U.S. Army Corps of Engineers, a Contractor agreed to construct facilities for support services, site logistics, and command in the Kingdom of Bahrain.  The Government assessed LDs for delayed substantial completion.  Several months later, after the Contractor had demobilized from the Project site, the Government issued an RFP for extra work.  The Government accepted the Contractor’s pricing proposal for the extra work and established a deadline for completion of the same.

In its Certified Claim and on Appeal to the Armed Services Board of Contract Appeals, the Contractor unsuccessfully argued the award of extra work extended the overall deadline for substantial completion of the original scope of work.  The bilateral Modification for the extra work provided in part, “This Period of Performance covers work under this modification only, not for the overall contract.”

The Board’s opinion doesn’t discuss what sort of extra work was performed.  Presumably, the use or benefit of the overall Project did not depend upon completion of the extra work.

Appeal of American International Contractors, Inc., Armed Services Board of Contract Appeals Nos. 60948 and 61166 (May 29, 2018)

Published On: October 1, 2018

Share This Story, Choose Your Platform!

  • Sum Certain Blog Post

Jurisdiction is Power

August 27, 2023|

Not bad power, but the ability of a decision-maker (e.g., court) to decide which side is right (or which is more correct). […]

  • Heavy Construction Law | Mediation Melee | Roads & Bridges

Roads & Bridges | Mediation Melee

June 13, 2023|

MEDIATION MELEE| An arbitration case can be costly

Arbitration can be a bridge over troubled waters. In this crossing, the parties argued over […]

  • Written Notice | Roads & Bridges Article | Jon Straw

Roads & Bridges | Written Notice

April 2, 2023|

WRITTEN NOTICE | Beware that strict compliance of the contract might be required.

When an owner replaced a contractor for significant safety violations, […]

Share This Story, Choose Your Platform!