As of Jan. 1, 2023, pay-if-paid clauses are unenforceable, regardless of whether a surety/payment bond claim is involved. This is only for subcontracts created on/after 1/1/23.
Also for subcontracts created on/after 1/1/23, the prime must specifically identify and notify the sub of withholding as underlined below.
Per Va Code 11-4.6(C), for any withholding, the prime “shall notify the subcontractor, in writing, of his intention to withhold all or a part of the subcontractor’s payment with the reason for nonpayment, specifically identifying the contractual noncompliance, the dollar amount being withheld, and the lower-tier subcontractor responsible for the contractual noncompliance.”
Per Va Code 2.2-4354(1), (SB 550) Requires construction contracts awarded by state or local government agencies “as well as certain private construction contracts in which there is at least one general contractor and one subcontractor” to include a payment clause that obligates the contractors to be liable for the entire amount owed to any subcontractor with which it contracts. The bill provides that “a contractor shall not be liable for amounts otherwise reducible due to the subcontractor’s noncompliance with the terms of the contract; however, the contractor must notify the subcontractor in writing of the contractor’s intent to withhold all or a part of the subcontractor’s payment with the reason for such nonpayment.”
The legislature has not yet, but is working, to reconcile the specificity required by one code section that the other section more broadly outlines.
Owner Nonpayment is No Defense to Miller Act Claim
As if you needed confirmation that the Federal Miller Act is a powerful tool for unpaid subcontractors, this is it. Even when a Prime ordered and accepted the Sub’s work, but didn’t have to pay under the Subcontract, the Subcontractor still. . . .
Trust, but Verify
Rely at your own risk upon a Contracting Officer’s statements when statutes or contract provisions may conflict.
Payment for Verbal Changes When a Writing was “Required”
Even if your agreement can only be modified by a writing, you may still have a good argument to be paid for extra work.
Pirates and Arbitration
How does a pirate solve a dispute (besides walking the plank)?
Bases Covered?
Contractors, will your current insurance policy cover “your work” as a joint venture partner? The typical answer is NO.
Two Paths at the Same Time to the Same Place
“Two roads diverged in a wood, and . . .” the Prime Contractor had to take both roads at the same time to the same place.
Rules, Which Rules?
Good Idea: Include a choice of law clause in your contract to promote consistency and predictability (while reducing potential costs and risk).
Government Liability for Third-Party Delays
Generally, the Government is not responsible for delays caused by third parties, even other contractors at its own project site, unless the Government affirmatively indicates the site will be ready and available.
Keep a Pass-Thru Claim Burning, Don’t Extinguish Liability
Prime contractors, have you ever submitted a subcontractor’s claim to a public owner? Subcontractors, have you ever wanted to submit a claim against the government, but you had no contract with government?
