Has your work on a government contract ever been delayed by another contractor? Did you (the prime contractor) have no control over the other contractor or entity? Did the Government promise you the other contractor would not inhibit your work? If yes to all three, consider the following success story of a Contractor’s recovery for delays against the Government caused by a third-party:
The successful Contractor under an IDIQ contract to perform canal excavation and sediment removal for the Department of Agriculture in St. Bernard Parish, Louisiana. Contractor encountered delays due to the continued presence of another contractor under a separate government contract at the same project site.
Key to the recovery was that during pre-bid site visit, the Contractor asked if the third-party’s work would be complete prior to the Contractor starting work. The Government replied, “Yes!” Fortunately for the Contractor, the pre-bid Q&A’s were made a part of the Contract by the Government’s own express direction.
Generally, the Government is not responsible for delays caused by third parties, even other contractors at its own project site, unless the Government affirmatively indicates the site will be ready and available.
The Civilian Board of Contract Appeals found the pre-bid Q&A’s were sufficient to establish a warranty by the Government that the site would be available. The Contractor recovered from the Government for the delays caused by the third-party contractor.
Roads& Bridges | Confusing Waters
CONFUSING WATERS | A Supreme Court ruling leaves room for ambiguity
What happens when there may be a “significant nexus” between “adjacent” and/or […]
Roads & Bridges | Authority Defined
AUTHORITY DEFINED | The Law of Agency is Important to Understand
For any project, this Russian proverb is helpful: Doveryay, no proveryay – […]
Jurisdiction is Power
Not bad power, but the ability of a decision-maker (e.g., court) to decide which side is right (or which is more correct). […]
Roads & Bridges | Defining Labor
DEFINING LABOR | How the Miller Act continues to shape the industry
In the late 1700s, risks of nonpayment caused a shortage of […]
Roads & Bridges | Mediation Melee
MEDIATION MELEE| An arbitration case can be costly
Arbitration can be a bridge over troubled waters. In this crossing, the parties argued over […]
Roads & Bridges | Written Notice
WRITTEN NOTICE | Beware that strict compliance of the contract might be required.
When an owner replaced a contractor for significant safety violations, […]
Roads & Bridges | Mommie Dearest
MOMMY DEAREST | The story of an ESA without a MOM
Nobody enters this world, or a contract, without a mother: There can […]
IIJA | Does Closing a “Giant Loophole” Cost Contractors?
A recent article published by Roads and Bridges magazine reports that the Office of Management and Budget is working to broaden the scope […]
Roads & Bridges | Buy American Plan Gets an Update
BUY AMERICAN PLAN GETS AN UPDATE
The Office of Management and Budget is developing standards to replace the current Buy […]

Jonathan J. Straw
Blog Author
Contact Jonathan
Partner | KraftsonCaudle.com
Download Jon’s Bio
