Appealing a Contracting Officer’s Final Decision is a rejection of any offer of payment or settlement included therein.
In a recent example of this, a contractor agreed to renovate a portion of a VA hospital in Fayetteville, Arkansas. After contract award, the VA notified the contractor of extra asbestos abatement. The contractor provided a price to perform the extra work but the VA issued a unilateral modification for a lesser amount. The contractor performed the extra work and submitted a certified claim.
The CO issued a Final Decision agreeing to only a portion of the claim and issued a draft modification. The contractor countered by proposing a reservation of its rights so that it could accept the partial payment and preserve a future appeal for the balance. The CO rejected the contractor’s proposal and, effectively, conditioned the partial payment upon the contractor’s waiver of appeal.
Without the reservation of rights, the contractor had only three options:
- Accept the partial payment and have no appeal;
- Appeal the entire claim; or
- Walk away.
BES Design/Build, LLC v. Department of Veterans Affairs, Civilian Board of Contract Appeals 5640 (Aug. 29, 2017)
Government’s Negligent Estimate a Trick?
The Government’s negligent estimate failed to provide the “most current information available.”
Prime Contractor Had No Duty to Help Surety Investigate Sub’s Default
We all know what happens when we “ASS-U-ME” something. So, we should all carefully avoid assuming things unnecessarily.
It’s Good to Be the King
Mel Brooks in the movie History of the World: Part I (1981) said it best – “It’s good to be the King.” It’s also true when asserting claims against the State or an arm or agent of the State.
Smoke Without Fire: Damage from Concrete Dust Covered by Insurance
You’ve heard, “where there’s smoke, there’s fire.” In this instance, the smoke was concrete dust that damaged a warehouse full of aircraft […]
Changes Made After Substantial Completion Did Not Extend Overall Project Time
Contractors take heed – a time extension may be issued after substantial completion for specific work and the Government can still assess […]
One-Sided Construction Arbitration Clause Valid in Virginia
When it’s time to butt heads, know how the local turf (court) will interpret the clause.
Manage the Risk of Construction Changes
Almost any problem on a construction project can be traced to one of two things: changes or delays (even delays are really just changes). As in life, embrace and manage the change don’t run from it.
Want Your Profit? Prove a Constructive Change, Not a Suspension of Work.
What’s the Difference Between a Suspension of Work and a Constructive Change? For federal contractors, there are two main differences: . . .
No Special Defenses to Arbitration Agreements
Arbitration agreements, whether they are separate or part of a larger agreement, are contracts – an enforceable set of promises between parties. […]
