Has your work on a government contract ever been delayed by another contractor? Did you (the prime contractor) have no control over the other contractor or entity? Did the Government promise you the other contractor would not inhibit your work? If yes to all three, consider the following success story of a Contractor’s recovery for delays against the Government caused by a third-party:
The successful Contractor under an IDIQ contract to perform canal excavation and sediment removal for the Department of Agriculture in St. Bernard Parish, Louisiana. Contractor encountered delays due to the continued presence of another contractor under a separate government contract at the same project site.
Key to the recovery was that during pre-bid site visit, the Contractor asked if the third-party’s work would be complete prior to the Contractor starting work. The Government replied, “Yes!” Fortunately for the Contractor, the pre-bid Q&A’s were made a part of the Contract by the Government’s own express direction.
Generally, the Government is not responsible for delays caused by third parties, even other contractors at its own project site, unless the Government affirmatively indicates the site will be ready and available.
The Civilian Board of Contract Appeals found the pre-bid Q&A’s were sufficient to establish a warranty by the Government that the site would be available. The Contractor recovered from the Government for the delays caused by the third-party contractor.
Prime Contractor Had No Duty to Help Surety Investigate Sub’s Default
We all know what happens when we “ASS-U-ME” something. So, we should all carefully avoid assuming things unnecessarily.
It’s Good to Be the King
Mel Brooks in the movie History of the World: Part I (1981) said it best – “It’s good to be the King.” It’s also true when asserting claims against the State or an arm or agent of the State.
Smoke Without Fire: Damage from Concrete Dust Covered by Insurance
You’ve heard, “where there’s smoke, there’s fire.” In this instance, the smoke was concrete dust that damaged a warehouse full of aircraft […]
Changes Made After Substantial Completion Did Not Extend Overall Project Time
Contractors take heed – a time extension may be issued after substantial completion for specific work and the Government can still assess […]
One-Sided Construction Arbitration Clause Valid in Virginia
When it’s time to butt heads, know how the local turf (court) will interpret the clause.
Manage the Risk of Construction Changes
Almost any problem on a construction project can be traced to one of two things: changes or delays (even delays are really just changes). As in life, embrace and manage the change don’t run from it.
Want Your Profit? Prove a Constructive Change, Not a Suspension of Work.
What’s the Difference Between a Suspension of Work and a Constructive Change? For federal contractors, there are two main differences: . . .
No Special Defenses to Arbitration Agreements
Arbitration agreements, whether they are separate or part of a larger agreement, are contracts – an enforceable set of promises between parties. […]
How to Find (and Confirm) the Plain Meaning in a Contract
Contract formation confirms the parties understand and agree to all the essential terms. When that understanding and agreement fades, how do you […]
