Contractors take heed – a time extension may be issued after substantial completion for specific work and the Government can still assess liquidated damages.
Under a contract with the U.S. Army Corps of Engineers, a Contractor agreed to construct facilities for support services, site logistics, and command in the Kingdom of Bahrain. The Government assessed LDs for delayed substantial completion. Several months later, after the Contractor had demobilized from the Project site, the Government issued an RFP for extra work. The Government accepted the Contractor’s pricing proposal for the extra work and established a deadline for completion of the same.
In its Certified Claim and on Appeal to the Armed Services Board of Contract Appeals, the Contractor unsuccessfully argued the award of extra work extended the overall deadline for substantial completion of the original scope of work. The bilateral Modification for the extra work provided in part, “This Period of Performance covers work under this modification only, not for the overall contract.”
The Board’s opinion doesn’t discuss what sort of extra work was performed. Presumably, the use or benefit of the overall Project did not depend upon completion of the extra work.
Construction Contracting Without Relief Clauses During COVID-19
What to do if your contract lacks the parts to handle COVID-19? Considerations for creating new contracts during COVID-19.
Your Contract Can Handle COVID-19
Uncertainty and risk are not new or novel to contractors. Contracts reduce uncertainty and share the risk of doing or providing something. COVID-19 may have contributed to, but it has not single-handedly created, uncertainty and risk.
Contractors Can Use RFI to Notify the Government
The Board (and the government) should not elevate form over substance in evaluating the sufficiency of a contractor’s notice.
Taxes Due!
It’s tax season again, so it’s time to pay the piper.
Contractor Wins when Government Reconsiders Accord
Ever had buyer’s remorse or second-guessed a decision? When the U.S. Army Corps of Engineers did that, a Contractor won its claim […]
Claim Certified with Digital Signature Deemed OK
The law is not a trend-setter. It doesn’t readily change or adapt to tech. So, a commonplace practice in business became a dispute when a claimant digitally certified a claim under the Contract Disputes Act.
Acceptance and Intervening Cause Avoided Construction Warranty Claim
Like cars, computers, and appliances, construction projects include warranties too. Similarly, construction project warranties are limited to causes within the contractor’s control […]
Insurance Company Had No Duty to Defend Under Eight Corners Rule
To decide if an insurer has a duty to defend, a Virginia State or Federal Court may only look at the allegations in the complaint and the insurance policy to determine if a judgment against the insured will be covered by the policy.
Owner SOL When Mandatory Mediation Didn’t Toll Statute of Limitations
Contract interpretation strives to find the meaning of all parts together.
