What’s the difference between a suspension of work and a constructive change? For federal contractors, there are two important differences:
- If you want profit, prove a constructive change.
- If any other contract clause affords an equitable adjustment (e.g., Changes Clause), the Suspension of Work clause won’t help you.
To recover from a suspension of work, a contractor must show:
- Contract performance was delayed;
- Government directly caused the delay;
- The delay was for an unreasonable period of time; and
- The contractor suffered damages therefrom (excluding profit); and
- No other clause provides an equitable adjustment to the Contractor
To prove a constructive change, a contractor must show:
- Any written or oral order from the Contracting Officer;
- Not a directed change;
- That caused a change;
- Contractor gave timely notice that it considered the order as a change; and
- The contractor suffered damages therefrom.
In a recent Civilian Board of Contract Appeals decision, the Board agreed with the contractor in finding an unreasonable delay (179 days) and awarded damages for a suspension of the work. In the same decision, the Board also found a constructive change in the contractor’s favor. The Board did not discuss why the suspension of work clause prevailed when the contractor may have been able to show a constructive change (unless, perhaps, notice of a constructive change was inadequate).
BCPeabody Construction Services, Inc. v. Dept. of Veterans Affairs, CBCA No. 5410, March 26, 2018
Government Contract Claims: When Appeal is Rejection of Settlement
Without a reservation of rights, appealing a Contracting Officer’s Final Decision is a rejection of any offer of payment or settlement included therein. So, the contractor had only three options.
Linking Obligations
If you want to bind the subcontractor to the prime in every way the same as the prime is bound to the owner, then the incorporation clause of the subcontract should be: . . .
Termination of Government Contracts for Convenience (T4C)
Imagine you’re a Government Contractor under a firm, fixed-price contract and you’ve done nothing wrong. Nevertheless, the Government has decided to unilaterally end its contract with you. Yes, the Government can do this...
Government Contractors: Build a Snowman in August
As a Government Contractor, when have you agreed to perform a certain way, but later realized that another way is better for everybody? When the Government agrees, expressly or impliedly, to the alternative performance, it waives a credit for the unperformed work.
Construction Dispute Settlement: Dealing with Details
Reap the benefits of settling a construction dispute by doing these things.
E-mail Signature Not Enough to Certify a Claim
Construction project professionals routinely send e-mails with “signatures,” which typically include the sender’s typewritten name, title, contact information, and/or company logo. But, this sort of e-mail “signature” is not enough to certify a claim to the Government.
Government Contractors: Ask for a “Sum Certain” in Your Claim
If your Claim includes an item for damages with an amount “TBD,” you could lose the entire Claim.
Contractors: Be Aware When Contracting with Virginia Public Agencies
Without a valid contract, a Virginia public entity has no duty to to pay for any of your work.
Constructive Acceleration
Contractors know that time is money. So, the point is clear when expressly told to “Speed Up! Go Faster!”
But, what do you […]
