Contractors know that time is money. So, the point is clear when expressly told to “Speed Up! Go Faster!”
But, what do you do when the Owner says, “You must still meet the deadline and I’m not giving you any more time.” Preserve and pursue a claim against the Owner for constructive acceleration.
Constructive acceleration occurs when the owner or government demands compliance with an original contract deadline, despite a delay. In such cases, the contractor may be entitled to reimbursement for expenses actually and reasonably incurred in complying with an (implied) acceleration order.
But, the Contractor must prove:
- Excusable Delay: a delay that is neither the fault of the owner or contractor;
- Request: The Contractor timely and sufficiently requested more time;
- Denial: Owner denied or failed to timely respond to Contractor’s request for more time;
- Demand: Owner demanded Contractor meet deadline;
- Timely Notice: Contractor timely notified Owner that Contractor understood the Owner’s demand as constructive acceleration; and
- Damages: Contractor incurred damages due to Owner’s unreasonable demand(s).
Roads & Bridges | Award Upheld in W. Va. Caisson Dispute
AWARD UPHELD IN W.VA. CAISSON DISPUTE
Federal court reinforces high bar for overturning arbitration
In 2018, the West Virginia Department of Highways (DOH) awarded […]
Roads & Bridges |Let the Contract Lead
LET THE CONTRACT LEAD
Documents offer guidance needed to manage risk without derailing projects
Construction is an industry of managed risk. Whether the prices […]
Roads & Bridges | When is an Invoice Really an Invoice?
WHEN IS AN INVOICE REALLY AN INVOICE?
All court decisions are opinions. Appellate court decisions are typically made by a panel of three […]
Roads & Bridges | Clarifying Punitive Damages
CLARIFYING PUNITIVE DAMAGES
In June 2021, the South Dakota Department of Transportation contracted for the demolition and construction of a bridge on State […]
Roads & Bridges | When Approximate Means Assumed Risk
WHEN APPROXIMATE MEANS ASSUMED RISK
A New York Court Shows How Performance Specifications Can Leave Contractors Holding the Bag
Sometimes when we are told […]
Roads & Bridges | From Roman Arches to AI
FROM ROMAN ARCHES TO AI
Can Construction Evolve Without Risk?
The construction industry blends old with new. From ancient Roman archways and aqueducts and […]
Roads & Bridges | Caught in the Middle
CAUGHT IN THE MIDDLE
New Mexico bridge case highlights the importance of written agreements for changes and delay compensation
In construction contracting, hope for […]
Roads & Bridges | Wait and It’s Waived
WAIT AND IT’S WAIVED
Roads & Bridges | Supreme Court Ruling on Arbitration Delay
Don’t wait to arbitrate! Progressing too far down the litigation […]
Roads & Bridges | Court Defines When Contractors Can Withdraw Due to Mistakes
BIDDING BLUNDER
Roads & Bridges | Court Defines When Contractors Can Withdraw Due to Mistakes
For over 125 years, the vast majority of jurisdictions […]
