Has your work on a government contract ever been delayed by another contractor? Did you (the prime contractor) have no control over the other contractor or entity? Did the Government promise you the other contractor would not inhibit your work? If yes to all three, consider the following success story of a Contractor’s recovery for delays against the Government caused by a third-party:
The successful Contractor under an IDIQ contract to perform canal excavation and sediment removal for the Department of Agriculture in St. Bernard Parish, Louisiana. Contractor encountered delays due to the continued presence of another contractor under a separate government contract at the same project site.
Key to the recovery was that during pre-bid site visit, the Contractor asked if the third-party’s work would be complete prior to the Contractor starting work. The Government replied, “Yes!” Fortunately for the Contractor, the pre-bid Q&A’s were made a part of the Contract by the Government’s own express direction.
Generally, the Government is not responsible for delays caused by third parties, even other contractors at its own project site, unless the Government affirmatively indicates the site will be ready and available.
The Civilian Board of Contract Appeals found the pre-bid Q&A’s were sufficient to establish a warranty by the Government that the site would be available. The Contractor recovered from the Government for the delays caused by the third-party contractor.
Pay-If-Paid Unenforceable in Virginia Starting Jan. 1, 2023
As of Jan. 1, 2023, pay-if-paid clauses are unenforceable, regardless of whether a surety/payment bond claim is involved. This is only for […]
How Short is Too Short
A limitations period is too short when it’s unreasonably short.
Construction Contracting Without Relief Clauses During COVID-19
What to do if your contract lacks the parts to handle COVID-19? Considerations for creating new contracts during COVID-19.
Your Contract Can Handle COVID-19
Uncertainty and risk are not new or novel to contractors. Contracts reduce uncertainty and share the risk of doing or providing something. COVID-19 may have contributed to, but it has not single-handedly created, uncertainty and risk.
Contractors Can Use RFI to Notify the Government
The Board (and the government) should not elevate form over substance in evaluating the sufficiency of a contractor’s notice.
Taxes Due!
It’s tax season again, so it’s time to pay the piper.
Contractor Wins when Government Reconsiders Accord
Ever had buyer’s remorse or second-guessed a decision? When the U.S. Army Corps of Engineers did that, a Contractor won its claim […]
Claim Certified with Digital Signature Deemed OK
The law is not a trend-setter. It doesn’t readily change or adapt to tech. So, a commonplace practice in business became a dispute when a claimant digitally certified a claim under the Contract Disputes Act.
Acceptance and Intervening Cause Avoided Construction Warranty Claim
Like cars, computers, and appliances, construction projects include warranties too. Similarly, construction project warranties are limited to causes within the contractor’s control […]
