Has your work on a government contract ever been delayed by another contractor? Did you (the prime contractor) have no control over the other contractor or entity? Did the Government promise you the other contractor would not inhibit your work? If yes to all three, consider the following success story of a Contractor’s recovery for delays against the Government caused by a third-party:
The successful Contractor under an IDIQ contract to perform canal excavation and sediment removal for the Department of Agriculture in St. Bernard Parish, Louisiana. Contractor encountered delays due to the continued presence of another contractor under a separate government contract at the same project site.
Key to the recovery was that during pre-bid site visit, the Contractor asked if the third-party’s work would be complete prior to the Contractor starting work. The Government replied, “Yes!” Fortunately for the Contractor, the pre-bid Q&A’s were made a part of the Contract by the Government’s own express direction.
Generally, the Government is not responsible for delays caused by third parties, even other contractors at its own project site, unless the Government affirmatively indicates the site will be ready and available.
The Civilian Board of Contract Appeals found the pre-bid Q&A’s were sufficient to establish a warranty by the Government that the site would be available. The Contractor recovered from the Government for the delays caused by the third-party contractor.
Linking Obligations
If you want to bind the subcontractor to the prime in every way the same as the prime is bound to the owner, then the incorporation clause of the subcontract should be: . . .
Termination of Government Contracts for Convenience (T4C)
Imagine you’re a Government Contractor under a firm, fixed-price contract and you’ve done nothing wrong. Nevertheless, the Government has decided to unilaterally end its contract with you. Yes, the Government can do this...
Government Contractors: Build a Snowman in August
As a Government Contractor, when have you agreed to perform a certain way, but later realized that another way is better for everybody? When the Government agrees, expressly or impliedly, to the alternative performance, it waives a credit for the unperformed work.
Construction Dispute Settlement: Dealing with Details
Reap the benefits of settling a construction dispute by doing these things.
E-mail Signature Not Enough to Certify a Claim
Construction project professionals routinely send e-mails with “signatures,” which typically include the sender’s typewritten name, title, contact information, and/or company logo. But, this sort of e-mail “signature” is not enough to certify a claim to the Government.
Government Contractors: Ask for a “Sum Certain” in Your Claim
If your Claim includes an item for damages with an amount “TBD,” you could lose the entire Claim.
Contractors: Be Aware When Contracting with Virginia Public Agencies
Without a valid contract, a Virginia public entity has no duty to to pay for any of your work.
Constructive Acceleration
Contractors know that time is money. So, the point is clear when expressly told to “Speed Up! Go Faster!”
But, what do you […]
Construction Contracts & Whodunit
Imagine reading a crime novel and just when you think you figured out whodunit, a plot twist suggests a different culprit. In construction contracting, finding the right answer can be a difficult task when
