Has your work on a government contract ever been delayed by another contractor? Did you (the prime contractor) have no control over the other contractor or entity? Did the Government promise you the other contractor would not inhibit your work? If yes to all three, consider the following success story of a Contractor’s recovery for delays against the Government caused by a third-party:
The successful Contractor under an IDIQ contract to perform canal excavation and sediment removal for the Department of Agriculture in St. Bernard Parish, Louisiana. Contractor encountered delays due to the continued presence of another contractor under a separate government contract at the same project site.
Key to the recovery was that during pre-bid site visit, the Contractor asked if the third-party’s work would be complete prior to the Contractor starting work. The Government replied, “Yes!” Fortunately for the Contractor, the pre-bid Q&A’s were made a part of the Contract by the Government’s own express direction.
Generally, the Government is not responsible for delays caused by third parties, even other contractors at its own project site, unless the Government affirmatively indicates the site will be ready and available.
The Civilian Board of Contract Appeals found the pre-bid Q&A’s were sufficient to establish a warranty by the Government that the site would be available. The Contractor recovered from the Government for the delays caused by the third-party contractor.
FEDERAL CONTRACT TERMINATION OR MODIFICATION
The White House has directed Agency heads to “terminate or modify . . . covered contracts.” With some exceptions, there are […]
Roads & Bridges | Maximizing Damage Recovery
MAXIMIZING DAMAGE RECOVERY
Tracking Costs, Avoiding Duplication in Liquidated and Actual Damage Claims
A County and Contractor contracted for construction of a road and […]
Roads & Bridges | Roadwork, Delays and Disputes
ROADWORK, DELAYS, AND DISPUTES
The Subcontract Case In Pecos County, Texas
“Road construction is ubiquitous in our society. . . .” C&C Road […]
Roads & Bridges | Understanding Sovereign Immunity
UNDERSTANDING SOVEREIGN IMMUNITY| Public Contracts and Lessons from Recent Texas Cases
Generally, governmental entities are immune from lawsuits. One exception is contractual. If […]
Roads & Bridges | Indiana Court Upholds Broad ND4D Clause
INDIANA COURT UPHOLDS BROAD ND4D CLAUSE | Ruling Precludes Subcontractor Claims for Delay and Acceleration Damages
This is the story of an Indiana […]
Roads & Bridges | Some Conditions Apply
SOME CONDITIONS APPLY | The scope of insurance policy coverage and what the terms dictate
At some time or another, many have tried […]
Roads & Bridges | Contract Termination
CONTRACT TERMINATION | An unpredictable case teaches hard lessons to each party involved
Court decisions are “opinions.” There are majority and dissenting (disagreeing) […]
Roads & Bridges | Good Faith and Fair Dealing
GOOD FAITH AND FAIR DEALING | How Do You Prove a Party Has Failed to Act Based Upon an Ulterior Motive?
The duty […]
Roads & Bridges | Not Another Notice Story
NOT ANOTHER NOTICE STORY| This Defensive Argument Seems to be on the Rise
AS I CONSIDERED the subject matter for this column, I […]
