During a recent soccer game, my seven-year-old son took the ball squarely in the face. But, he walked it off and continued playing. Contractors must do the same with changes.
In 2006, under a contract with NAVFAC for repairs to a wastewater treatment system at Naval Station Guantanamo Bay Cuba, the Contractor encountered differing site conditions. NAVFAC did not issue a suspension or stop work order, but the Contractor stopped working awaiting responses to RFIs. NAVFAC did not respond to all the RFIs. So, the Contractor submitted a certified claim, but the Contractor never resumed work. The Contractor should have continued working.
Under the Federal Acquisition Regulations, the Contractor is obligated to “prosecute the work diligently” and continue performance pending the outcome of a claim. (FAR 52.211-10 and 52.233-1(i)). Doing so not only mitigates potential delays and damages, but it ensures that when a claim is submitted, a “sum certain” (i.e., showing of damage) is possible.
In this case, the Contractor’s claim submission was premature and the Contractor’s refusal to perform directed or constructive changes pending the promise of payment precluded the ASBCA from having any power to resolve the dispute. The ASBCA dismissed the Contractor’s appeal because the Contractor sought future damages for work it had not yet performed. At worst, NAVFAC could have terminated the Contractor for default.
Appeal of Islands Mechanical Contractor, Inc., ASBCA No. 59655 (April 13, 2017)
Your Contract Can Handle COVID-19
Uncertainty and risk are not new or novel to contractors. Contracts reduce uncertainty and share the risk of doing or providing something. COVID-19 may have contributed to, but it has not single-handedly created, uncertainty and risk.
Contractors Can Use RFI to Notify the Government
The Board (and the government) should not elevate form over substance in evaluating the sufficiency of a contractor’s notice.
Taxes Due!
It’s tax season again, so it’s time to pay the piper.
Contractor Wins when Government Reconsiders Accord
Ever had buyer’s remorse or second-guessed a decision? When the U.S. Army Corps of Engineers did that, a Contractor won its claim […]
Claim Certified with Digital Signature Deemed OK
The law is not a trend-setter. It doesn’t readily change or adapt to tech. So, a commonplace practice in business became a dispute when a claimant digitally certified a claim under the Contract Disputes Act.
Acceptance and Intervening Cause Avoided Construction Warranty Claim
Like cars, computers, and appliances, construction projects include warranties too. Similarly, construction project warranties are limited to causes within the contractor’s control […]
Insurance Company Had No Duty to Defend Under Eight Corners Rule
To decide if an insurer has a duty to defend, a Virginia State or Federal Court may only look at the allegations in the complaint and the insurance policy to determine if a judgment against the insured will be covered by the policy.
Owner SOL When Mandatory Mediation Didn’t Toll Statute of Limitations
Contract interpretation strives to find the meaning of all parts together.
Government Must Review Claims in Good Faith, Not “Conjure Up” a “Baseless Retaliation”
A contracting officer’s review of certified claims submitted in good faith is not intended to be a negotiating game where the agency may deny meritorious claims to gain leverage over the contractor.
