What’s the difference between a suspension of work and a constructive change? For federal contractors, there are two important differences:
- If you want profit, prove a constructive change.
- If any other contract clause affords an equitable adjustment (e.g., Changes Clause), the Suspension of Work clause won’t help you.
To recover from a suspension of work, a contractor must show:
- Contract performance was delayed;
- Government directly caused the delay;
- The delay was for an unreasonable period of time; and
- The contractor suffered damages therefrom (excluding profit); and
- No other clause provides an equitable adjustment to the Contractor
To prove a constructive change, a contractor must show:
- Any written or oral order from the Contracting Officer;
- Not a directed change;
- That caused a change;
- Contractor gave timely notice that it considered the order as a change; and
- The contractor suffered damages therefrom.
In a recent Civilian Board of Contract Appeals decision, the Board agreed with the contractor in finding an unreasonable delay (179 days) and awarded damages for a suspension of the work. In the same decision, the Board also found a constructive change in the contractor’s favor. The Board did not discuss why the suspension of work clause prevailed when the contractor may have been able to show a constructive change (unless, perhaps, notice of a constructive change was inadequate).
BCPeabody Construction Services, Inc. v. Dept. of Veterans Affairs, CBCA No. 5410, March 26, 2018
FEDERAL CONTRACT TERMINATION OR MODIFICATION
The White House has directed Agency heads to “terminate or modify . . . covered contracts.” With some exceptions, there are […]
Roads & Bridges | Maximizing Damage Recovery
MAXIMIZING DAMAGE RECOVERY
Tracking Costs, Avoiding Duplication in Liquidated and Actual Damage Claims
A County and Contractor contracted for construction of a road and […]
Roads & Bridges | Roadwork, Delays and Disputes
ROADWORK, DELAYS, AND DISPUTES
The Subcontract Case In Pecos County, Texas
“Road construction is ubiquitous in our society. . . .” C&C Road […]
Roads & Bridges | Understanding Sovereign Immunity
UNDERSTANDING SOVEREIGN IMMUNITY| Public Contracts and Lessons from Recent Texas Cases
Generally, governmental entities are immune from lawsuits. One exception is contractual. If […]
Roads & Bridges | Indiana Court Upholds Broad ND4D Clause
INDIANA COURT UPHOLDS BROAD ND4D CLAUSE | Ruling Precludes Subcontractor Claims for Delay and Acceleration Damages
This is the story of an Indiana […]
Roads & Bridges | Some Conditions Apply
SOME CONDITIONS APPLY | The scope of insurance policy coverage and what the terms dictate
At some time or another, many have tried […]
Roads & Bridges | Contract Termination
CONTRACT TERMINATION | An unpredictable case teaches hard lessons to each party involved
Court decisions are “opinions.” There are majority and dissenting (disagreeing) […]
Roads & Bridges | Good Faith and Fair Dealing
GOOD FAITH AND FAIR DEALING | How Do You Prove a Party Has Failed to Act Based Upon an Ulterior Motive?
The duty […]
Roads & Bridges | Not Another Notice Story
NOT ANOTHER NOTICE STORY| This Defensive Argument Seems to be on the Rise
AS I CONSIDERED the subject matter for this column, I […]
