Contractors know that time is money. So, the point is clear when expressly told to “Speed Up! Go Faster!”
But, what do you do when the Owner says, “You must still meet the deadline and I’m not giving you any more time.” Preserve and pursue a claim against the Owner for constructive acceleration.
Constructive acceleration occurs when the owner or government demands compliance with an original contract deadline, despite a delay. In such cases, the contractor may be entitled to reimbursement for expenses actually and reasonably incurred in complying with an (implied) acceleration order.
But, the Contractor must prove:
- Excusable Delay: a delay that is neither the fault of the owner or contractor;
- Request: The Contractor timely and sufficiently requested more time;
- Denial: Owner denied or failed to timely respond to Contractor’s request for more time;
- Demand: Owner demanded Contractor meet deadline;
- Timely Notice: Contractor timely notified Owner that Contractor understood the Owner’s demand as constructive acceleration; and
- Damages: Contractor incurred damages due to Owner’s unreasonable demand(s).
Roads & Bridges | Wait and It’s Waived
WAIT AND IT’S WAIVED
Roads & Bridges | Supreme Court Ruling on Arbitration Delay
Don’t wait to arbitrate! Progressing too far down the litigation […]
Roads & Bridges | Court Defines When Contractors Can Withdraw Due to Mistakes
BIDDING BLUNDER
Roads & Bridges | Court Defines When Contractors Can Withdraw Due to Mistakes
For over 125 years, the vast majority of jurisdictions […]
FEDERAL CONTRACT TERMINATION OR MODIFICATION
The White House has directed Agency heads to “terminate or modify . . . covered contracts.” With some exceptions, there are […]
Roads & Bridges | Maximizing Damage Recovery
MAXIMIZING DAMAGE RECOVERY
Tracking Costs, Avoiding Duplication in Liquidated and Actual Damage Claims
A County and Contractor contracted for construction of a road and […]
Roads & Bridges | Roadwork, Delays and Disputes
ROADWORK, DELAYS, AND DISPUTES
The Subcontract Case In Pecos County, Texas
“Road construction is ubiquitous in our society. . . .” C&C Road […]
Roads & Bridges | Understanding Sovereign Immunity
UNDERSTANDING SOVEREIGN IMMUNITY| Public Contracts and Lessons from Recent Texas Cases
Generally, governmental entities are immune from lawsuits. One exception is contractual. If […]
Roads & Bridges | Indiana Court Upholds Broad ND4D Clause
INDIANA COURT UPHOLDS BROAD ND4D CLAUSE | Ruling Precludes Subcontractor Claims for Delay and Acceleration Damages
This is the story of an Indiana […]
Roads & Bridges | Some Conditions Apply
SOME CONDITIONS APPLY | The scope of insurance policy coverage and what the terms dictate
At some time or another, many have tried […]
Roads & Bridges | Contract Termination
CONTRACT TERMINATION | An unpredictable case teaches hard lessons to each party involved
Court decisions are “opinions.” There are majority and dissenting (disagreeing) […]
