Recently, I posted about the Spearin Doctrine, which says that if a contractor follows the owner’s plans and specifications and something doesn’t work, the contractor is generally not at fault. But, this only works if the contractor first follows the owner’s design. It doesn’t work when the owner’s design will work as is, but you think it could be better.
In recently denying an HVAC Contractor’s appeal, the Armed Services Board of Contract Appeals stated, “the government may require performance [either] in excess of, or below, the standard normally accepted in a trade.” In other words, the government need not follow the industry standard. It can do less or more.
Under a firm, fixed-price contract managed by the Army Corps of Engineers, the Contractor agreed to upgrade the HVAC equipment at a Child Development Center at a facility in Hanover, NH. The project was “limited by budget constraints,” but included work intended to remedy the “thermal discomfort” of the facility’s occupants.
The Contractor advised the Corps that certain design improvements would help the end-user. The Corps considered the advice, but rejected the Contractor’s suggestion. Thereafter, the Contractor “delayed the project because it disagreed with the government’s design choices.” Ultimately, the Corps terminated the Contractor for default.
Roads & Bridges | Caught in the Middle
CAUGHT IN THE MIDDLE
New Mexico bridge case highlights the importance of written agreements for changes and delay compensation
In construction contracting, hope for […]
Roads & Bridges | Wait and It’s Waived
WAIT AND IT’S WAIVED
Roads & Bridges | Supreme Court Ruling on Arbitration Delay
Don’t wait to arbitrate! Progressing too far down the litigation […]
Roads & Bridges | Court Defines When Contractors Can Withdraw Due to Mistakes
BIDDING BLUNDER
Roads & Bridges | Court Defines When Contractors Can Withdraw Due to Mistakes
For over 125 years, the vast majority of jurisdictions […]
FEDERAL CONTRACT TERMINATION OR MODIFICATION
The White House has directed Agency heads to “terminate or modify . . . covered contracts.” With some exceptions, there are […]
Roads & Bridges | Maximizing Damage Recovery
MAXIMIZING DAMAGE RECOVERY
Tracking Costs, Avoiding Duplication in Liquidated and Actual Damage Claims
A County and Contractor contracted for construction of a road and […]
Roads & Bridges | Roadwork, Delays and Disputes
ROADWORK, DELAYS, AND DISPUTES
The Subcontract Case In Pecos County, Texas
“Road construction is ubiquitous in our society. . . .” C&C Road […]
Roads & Bridges | Understanding Sovereign Immunity
UNDERSTANDING SOVEREIGN IMMUNITY| Public Contracts and Lessons from Recent Texas Cases
Generally, governmental entities are immune from lawsuits. One exception is contractual. If […]
Roads & Bridges | Indiana Court Upholds Broad ND4D Clause
INDIANA COURT UPHOLDS BROAD ND4D CLAUSE | Ruling Precludes Subcontractor Claims for Delay and Acceleration Damages
This is the story of an Indiana […]
Roads & Bridges | Some Conditions Apply
SOME CONDITIONS APPLY | The scope of insurance policy coverage and what the terms dictate
At some time or another, many have tried […]
